Texas Military Department (Texas) posted this RFP on Nov 4, 2026. Responses are due Mar 2, 2027. Category: Construction - Building. Questions are due 2027-01-08 16:00. Solicitation number TMD27-CFMO-0046265.
Per TGC 2269 and 437.054, the Texas Military Department (TMD) is seeking competitive sealed proposals from General Contractors to modernize the Texas Army National Guard Camp Mabry facility in Austin, Texas.
The General Contractor shall provide all materials, equipment, labor, coordination, and supervisory activities necessary to complete construction of the project. This project is part of the STAR program and will renovate an approximate 144,458 SF. Work includes general facility sustainment such as refinishing of interior surfaces, exterior doors, and resurfacing of pavement. Restoration of MEP, roof systems, and similar types of work. Modernization to include compliance with ADA standards and current building codes, required ATFP, and requirements of dual gender restrooms. Energy will provide restoration of electrical, HVAC, plumbing, and insulation which is beyond useful life and/or lacked maintenance.
The estimated construction budget for the services described in the Request for Proposal (RFP) is estimated Proposal Base is Twenty-Nine Million Dollars (**$29,000,000.00**) with the estimated Proposal Options Nine Hundred Seventy Thousand (**$970,000.00**).
General Contractors must request via email: FY27Building8RCMM@cfmo.mil.texas.gov the Drawings/Plans and Specifications electronically in digital format.
General Contractors MUST attend one (1) of the three (3) **MANDATORY** site visits
at 2200 West 35th Street, Austin, Texas, 78703. Failure to have an employee or authorized representative attend one of the three mandatory site visits on behalf of the prospective Respondent will result in disqualification of the Proposal. The site visits are public events; subcontractors are welcome to attend and network with prospective General Contractors.
Competitive Sealed Proposals for TMD26-CFMO-0046265 will be received by the TMD until **10:00 AM CT, Tuesday, March 2, 2027**, at Camp Mabry, Building 37, Austin, Texas 78703.
Summary fields on this page were extracted by AI from the bid documents. Always verify dates, amounts and requirements against the official solicitation.
In accordance with the provisions of Texas Government Code (TGC) §437.054 and §2269 Subchapter D, Competitive Sealed Proposal Method, and Rules and Procedures, the Texas Military Department (TMD) Construction and Facilities Maintenance Office (CFMO) is soliciting proposals for Camp Mabry Bldg. 8 JFHQ MM STAR located at 2200 West 35th Street, Austin, Texas 78703.
The Texas Military Department (TMD) is seeking competitive sealed proposals from General Contractors to modernize the Texas Army National Guard Camp Mabry facility in Austin, Texas.
The estimated construction budget for the services described in the Request for Proposal (RFP) is estimated Proposal Base is Twenty-Nine Million Dollars (**$29,000,000.00**) with the estimated Proposal Options Nine Hundred Seventy Thousand (**$970,000.00**).
The General Contractor shall provide all materials, equipment, labor, coordination, and supervisory activities necessary to complete construction of the project.
This project is part of the STAR program and will renovate an approximate 144,458 SF. Work includes general facility sustainment such as refinishing of interior surfaces, exterior doors, and resurfacing of pavement. Restoration of MEP, roof systems, and similar types of work. Modernization to include compliance with ADA standards and current building codes, required ATFP, and requirements of dual gender restrooms. Energy will provide restoration of electrical, HVAC, plumbing, and insulation which is beyond useful life and/or lacked maintenance.
Drawings and Specifications
General Contractors must request via email: FY27Building8RCMM@cfmo.mil.texas.gov the Drawings/Plans and Specifications electronically in digital format.
Submission
Competitive Sealed Proposals will be received by the TMD until **10:00 AM CT, Tuesday, March 2, 2027**, at Camp Mabry, Building 37, Austin, Texas 78703.
Site visits
General Contractors MUST attend one (1) of the three (3) **MANDATORY** site visits. Failure to have an employee or authorized representative attend one of the three mandatory site visits on behalf of the prospective Respondent will result in disqualification of the Proposal. The site visits are public events; subcontractors are welcome to attend and network with prospective General Contractors.
Contract term
Construction is required to commence on the date specified in the Notice to Proceed issued. The TMD will issue a Notice to Proceed within 90 days of the contract award. The Respondent will provide the performance period in calendar days in *Attachment A*, 2. Performance Period. The approximate project completion date is October 2028.
Sign up free to get these 9 documents.
Camp Mabry Bldg. 8 JFHQ Major Maintenance STAR Follow Solicitation - Texas Military Department, Texas
Full details, the documents and the posting link, plus saved bids and daily alerts for your team.
7 days free, no credit card. Already have an account? Log in
