6th Street Widening and Resurfacing CIGP

The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing:

6TH STREET WIDENING AND RESURFACING CIGP, FPID NO. 457424-1-54-01

The project is the widening and resurfacing of 6TH Street (Eastpoint, Fl) for approximately 0.149 miles from U.S. Highway 98 to Avenue A.

The project is the widening and resurfacing of 6TH Street (Eastpoint, Fl) for approximately 0.149 miles from U.S. Highway 98 to Avenue A. Other work includes necessary drainage improvements, upgraded signage and pavement markings and safety improvements.

All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant mix-Bituminous Course.

Substantial Completion date for this project will be 90 calendar days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at **$750.00 per day**.

Plans and specifications can be obtained by contacting Shannon Renfro with Dewberry at srenfro@dewberry.com. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.

Please indicate on the envelope that this is a sealed bid, for "6TH STREET WIDENING AND RESURFACING CIGP".

Bids will be received until **4:30 p.m. eastern time, on December 15, 2026**, at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on Wednesday, December 16, 2026, at the County Commission meeting at 34 Forbes Street, Apalachicola, FL.

The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening.

All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.